R2026-020 - Laserfiche WebLink

Home Browse Search

and of ati etements of additionaL time required, and copies of any supporting documents evidencing the amount or extension of time ctaimed to be due' 2 3. O-wn ers h"ip.ef-llgras-P"Loduc€d : Att writings, programs, data, pubtic records or other materiats prepared by the contractor and/orits consuttants or sub-ContractorS, in connection with the performance of this Agreement shatl, be the sol.e and absotute property of the county. 24. eonfid*e n-tlatily: The contractor, its emptoyees, sub-contractors, and their emptoyees shal'[ maintain the confidentiatity of al.t information provided by the County or acquired by the Contractor in performance of this Agreement, except upon the prior written consent of the Kittitas county Prosecuting Attorney or an order entered by a court after having acquired jurisdiction over the county. contractor shaU, immediatety give to the county notice of any judiciaI proceedings seeking disctosure of such information. contractor shatL indemnify and hoLd harmLess the county, its AdditionaI lnsured's, officiats, agents or emptoyees from al[ toss or expense' inctuding, but not timited to setttements, judgments, setoffs, attorneys'fees and costs resuLting from Contractor's breach of this provision' To the extent that any information obtained bythe Contractor is required to be shared with or provided to others by the terms of the Statement of the Work, this provision is not breached by such acts. 25. Notice: Except as set forth eLsewhere in the Agreement, for atl' purposes underthis Agreement' except service of process, notice shalL be given by the Contractor to the department head of the department for whom seryices ura |."nd.r*d, and to the Kittitas county commissioners' 205 W 5,h Ave, Suite 108, Etlensburg, WA 98926' Notice to the Contractorfor at[ purposes under this Agreement shail. be given to the address refLected on the signature page' Notice may be given by deLivery or by depositing in the u's. Mait, first ctass, postage prepaid' 26. geJ-er-abitity: lf any term or condition of this Agreement or the appl'ication thereof to any person(s) or circumstances is hetd invaLid, such invaLidity shatl not affect other terms' conditions or appl.ications which can be given effect without the invatid term, condition or application' To this end, the terms and conditions of this Agreement are dectared severable' 27. Wsee--Llane,o,us: 27.1 The county's faiture or delay to insist upon strict performance of any of the provisions of this Agreement or to exercise any rights or remedies under this Agreement shaLt not be construed as a waiver or reLinquishment to any extent of its right to assert or rely upon any such provisions, rights or remedies in that or any other Instance; rather the same shatl be and remain in futt force and effect. Kittitas County Professionat Services Agreement Pageilofl9