PSA Habitat Floral Ave Project - Laserfiche WebLink

Home Browse Search

The Contractor shall not be entitled to claim any such additional compensation, or extension of time, unless within thirty (30) days of the completion of the portion of the workfrom which the claim arose, and before final payment by the County, the Contractor has given the County a detailed written statement of each element of cost or other compensation requested and of all elements of additional time required, and copies of any supporting documents evidencing the amount or extension of time claimed to be due. 23. dwner5hip of Item Psoduced: All writings, programs, data, public records or other materials prepared by the Contractor and/or its consultants or sub -Contractors, in connection with the performance of this Agreement shall be the sole and absolute property of the County. 24. Confidentiality: The Contractor, its employees, sub -Contractors, and their employees shall maintain the confidentiality of all information provided by the County or acquired by the Contractor in performance of this Agreement, except upon the prior written consent of the Kittitas County Prosecuting Attorney or an order entered by a court after having acquired jurisdiction over the County. Contractor shall immediately give to the County notice of any judicial proceedings seeking disclosure of such information. Contractor shall indemnify and hold harmless the County, its Additional Insured's, officials, agents or employees from all loss or expense, including, but not limited to settlements, judgments, setoffs, attorneys' fees and costs resulting from Contractor's breach of this provision. To the extent that any information obtained bythe Contractor is required to be shared with or provided to others by the terms of the Statement of the Work, this provision is not breached by such acts. 25. Notice: Except as set forth elsewhere in the Agreement, for all purposes under this Agreement, except service of process, notice shall be given by the Contractor to the department head of the department for whom services are rendered, and to the Kittitas County Commissioners, 205 W 5th Ave, Suite 108, Ellensburg, WA 98926. Notice to the Contractor for all purposes under this Agreement shall be given to the address reflected on the signature page. Notice may be given by delivery or by depositing in the U.S. Mail, first class, postage prepaid. 26. Sev_erability: If any term or condition of this Agreement or the application thereof to any person(s) or circumstances is held invalid, such invalidity shall not affect other terms, conditions or applications which can be given effect without the invalid term, condition or application. To this end, the terms and conditions of this Agreement are declared severable. 27. Qgll n u : Kittitas County Professional Services Agreement Page 11 of 20