Signed PSA Weapon Storage - Laserfiche WebLink

Home Browse Search

22.2 22.3. Detailed Claim The Contra"tor shall not be entitled to claim any such additional compensation, or extension of time, unless within thirty (30) days of lhe completion of ine portion of the work from which the claim arose, and before final'payment by tire Coung, the Contractor has given the County a detailed written rt"t"rent of each element of cost or other compensation requested and of all elements of additional time required, and copies of any supporting documents evidencing the amount or extension of time claimed to be due. 23. Ownefslrip of ltems Produced: A1 writings, progra,iG]ffi]ufiili records or other materials prepared bY.lh* Contractor and/or its consultants or sub-Contractors, in eonnection with performance of this Agreemeni shall be the sole and absolute property of the County' Professional $ervices Agreement (rev. 09 124 1201 8\ Page 9 of 17 24. Confidenfiality,: The contractor, its employees, sub-contractors, and their employees shall maintain the confidentiality of att intormation provided by the county. or acquired by the contractor in puJo*"nce of this Agreement, except upon the prior written consent of the Kittitas County jtrosecuting Attorney"or rn order entered by a court after having acquired jurisdiction over the County. Contiactor shall immediate"ty give to lhe County notice of any judicial fro"""Oind" seeking disclosure of such intonnation. Contractor shall indemnif,T and hold hannless the Count|, iis Additional lnsureds, officials, agents or employees from all loss or expense, including, but not limited to settlements, judgments, setoffs, attorneys'fees and costs resulting from contractor's breach of this provision. To the extent that any information obtained ny ine contractor is required to be shared with or provided to others by the terms of the statement of the work, this provision is not breached by such acts. 25. Noticq: