Resolution 2025-085 - Laserfiche WebLink

Home Browse Search

20.4 The Contractor has or will obtain prior to the commencement date such licenses, permits and other authorizations from federal, state and other governmental authorities, as are necessary for the performance of its obligations under this Agreement' Z0.S The Contractor is not in violation of any applicable law, ordinance or regulation the consequence of which will or may materialiy affect Contractor's ability to perform. its obligations under tnis agieem"ni fn" Contractor is not subject to any order or judgment of any court, tribunal o, goi"rn*ental agency which materially and adversely affects its operations or assets in the State of Washington, or its abiliiy to perform its obligations under this Agreement. 20.6 None of the representations or warranties in this Agreemenf, .tnd none of the documents' statements, certificates or schedules furnished or to be furnished by Contractor pursuant hereto or in connection with the performance of the obligations contemplated under this Agreement, contains or will contain any untrue statemeit of a material fact or omits or will omit to state a material fact necessary to make the statements of fact contained therein not misleading. 21 . PatenUCopvriqht lnfringement: contractor will defend and indemnify the county from any claimed action, cause or demand brought againsl ihe county; to the extent such action is based on the claim that information supplied by the contractor infringes any patent or copyright The contractor will pay those costs and damages attributable to any such claims that are finally awarded against the county in any iction. such defense and payments are conditioned upon the following: 21.1 Contractor shall be notified promptly in writing by County of any notice of such claim 21.2 contractor shall have the right, hereunder, at"its option and expense, to obtain for the County the righi to continue using the iiformation, in the event such claim of infringement is made, provided no reduction in performance or loss results to the county. 22 Disputes: 221 22.2 General Differences between the Contractor and the County, arising under and by virtue of the Agreemenr Documents shall be brought to the attention of the County at the earliest possible time in order that such matters may OJ settted or other appropriate action promptly taken' Except for sucl- objections as are p,nud* of record in the manner hereinafter specified and within the time limits stated, the records, orders, instructions, and decisions of the Kittrtas county commissioners shal be final and conclusive. Notice of Potential Claims The contractor shall not be entifled to additional compensation which otheruirise may be payable or to extension of time for (1) any act or failure to act by the County, or (2) the happening of an1 event or occurrence, unless'the contractor has given the county a written Notice of Poientia Claim within ten (1Oj Aays of the commencemenl of the act, failure' or event giving rise to tht claim, and before final payment by the county. The written Notice of Potential claim shall se forth the reasons for which the contractor believes additional compensation or extension of timt is due, the nature of the cost involved, and insofar as possible, the amount of the potentialclaim Contractor shall keep full and complete daily records of the work performed, labor and materia used, and all costs and additionaltime claimed to be additional. Detailed Claim223