Grants & Contract Agreement (4) - Laserfiche WebLink

Home Browse Search

The Contractor shall not be entitled to claim any such additional compensation, or extension of time, unless within thirty (30) days of the completion of the portion of the work from which the claim arose, and before final payment by the County, the Contractor has given the County a detailed written statement of each element of cost or other compensation requested and of all elements of additional time required, and copies of any supporting documents evidencing the amount or extension of time claimed to be due. 23. Ownership of ltems Produced: AllrecordsorothermaterialspreparedbytheContractorand/oritsconsultants or sub-Contractors, in connection with performance of this Agreement shall be the sole and absolute property of the County. 24. Confidentialitv: fne Coltractor, its employees, sub-Contractors, and their employees shall maintain the confidentiality of all information provided by the County or acquired by the Contractor in performance of this Agreement, except upon the prior written ionsent of tl're Kittitas County Prosecuting Attorney or an order entered by a courtafter having acquired jurisdiction over the County. Contractor shall immediately give to the County notice of any judiciil proceedings seeking disclosure of such information. Contractor shall indemnify and hold harmless the bounty, its Additio-nal lnsure-d's, officials, agents or employees from all loss or expense, including, but not limited to setlements, judgments, setoffs, attorneys'fees and costs resulting from Contractor's breach of this provision. To the extent that jny information obtained by the Contractor is required to be shared with or provided to others by the terms of the Statement of the Work, this provision is not breached by such acts' 25. Notice: fxcept as set forth elsewhere in the Agreement, for all purposes under this Agreement, except service of process, notice shall be given by the Contractor to the department head of the department for whom services are rendered, and to thJKittitai County Commissioners,205 W 5th Ave, Suite 108, Ellensburg, WA 98926. Notice to the Contractor for all purposes under this Agreement shall be given to the address reflected on the signature page. Notice may be given by delivery or by depositing in the U.S. Mail, first class, postage prepaid. 26. Severability: tt any terrn or condition of this Agreement or the application thereof to any person(s) or circumstances is held invalid, such invalidity shall not affect other terms, conditions or applications which can be given effect without the invalid term, "ondition or application. To this end, the terms and conditions of this Agreement are declared severable. 27. Miscellaneous: 271 The County's failure or delay to insist upon strict performance of any of the provisions of this Agreemenior to exercise any rights or remedies under this Agreement shall not be construed as a waiver or relinquishment to any extent of its right to assert or rely upon any such provisions, rights or remedies in that or any other instance; rather the same shall be and remain in fullforce and effect. 27.2 This Agreement embodies the entire Agreement between the County and Contractor, and sup"rs6des any and all prior agreements, regarding the Work. No change, amendment or modification of any provisions of this Agreement shall be valid unless set forth in a written instrument signed by the party to be bound thereby. 27.3 The rights an-d remedies of the County set forth in any provision of this Agreement are in addition to and do not in any way limit any other rights of remedies afforded to the County by any other provisions of this Agreement, by any of Contraetor's Support or by law.