|
S S.2.2 The Contractor shall not knowingly, except by agreement or instruction of the Owner in writing, prematurely
<br />commence operations on the site or elsewhere prior to the effective date of insurance required by Article 1l to be
<br />fumished by the Contractor and Owner. The date of commencement of the Work shall not be changed by the
<br />effective date ofsuch insurance.
<br />$ S.2.3 The Contractor shall proceed expeditiously with adequate forces and shall achieve Substantial Completion
<br />within the Contract Time.
<br />$ 8.3 DELAYS AND EXTENSIONS OF TIME
<br />S S.3.1 If the Contractor is delayed at any time in the commencement or progtess of the Work by an act or neglect of
<br />the Owner or Architect, or of an employee of either, or of a separate contractor employed by the Owner; or by
<br />changes ordered in the Work; or by labor disputes, fire, unusual delay in deliveries, unavoidable casualties or other
<br />causes beyond the Contractor's control; or by delay authorized by the Owner pending mediation and arbitration; or
<br />by other causes that the Architect determines may justifu delay, then the Contract Time shall be extended by Change
<br />Order for such reasonable time as the Architect may determine.
<br />S S.3.2 Claims relating to time shall be made in accordance with applicable provisions of Article 15.
<br />$ 8.3.3 This Section 8.3 does not preclude recovery of damages for delay by either party under other provisions of
<br />the Contract Documents.
<br />ARTICLE 9 PAYMENTS AND COMPLETION
<br />$ 9.l CONTRACT SUM
<br />The Contract Sum is stated in the Agreement and, including authorized adjustments, is the total amount payable by
<br />the Owner to the Contractor for performance of the Work under the Contract Documents.
<br />$ 9.2 SCHEDULE OF VALUES
<br />Where the Contract is based on a stipulated sum or Guaranteed Maximum Price, the Contractor shall submit to the
<br />Architect, before the first Application for Payment, a schedule of values allocating the entire Contract Sum to the
<br />various portions of the Work and prepared in such form and supported by such data to substantiate its accuracy as
<br />the Architect may require. This schedule, unless objected to by the Architect, shall be used as a basis for reviewing
<br />the Contractor's Applications for Payment.
<br />$ 9.3 APPLTCATIONS FOR PAYMENT
<br />$ 9.3,1 At least ten days before the date established for each progress payment, the Contractor shall submit to the
<br />Architect an itemized Application for Payment prepared in accordance with the schedule of values, if required under
<br />Section 9.2, for completed portions of the Work. Such application shall be notarized, if required, and supported by
<br />such data substantiating the Contractor's right to payment as the Owner or Architect may require, such as copies of
<br />requisitions from Subcontractors and material suppliers, and shall reflect retainage if provided for in the Conhact
<br />Documents.
<br />S 9.3.1.1 As provided in Section 7.3.9, such applications may include requests for payment on account of changes in
<br />the Work that have been properly authorized by Construction Change Directives, or by interim determinations of the
<br />Architect, but not yet included in Change Orders.
<br />S 9.3.1,2 Applications for Payment shall not include requests for payment for portions of the Work for which the
<br />Contractor does not intend to pay a Subcontractor or material supplier, unless such Work has been performed by
<br />others whom the Contractor intends to pay.
<br />S 9.3.2 Unless otherwise provided in the Contract Documents, payments shall be made on account of materials and
<br />equipment delivered and suitably stored at the site for subsequent incorporation in the Work. If approved in advance
<br />by the Owner, payment may similarly be made for materials and equipment suitably stored off the site at a location
<br />agreed upon in writing. Payment for materials and equipment stored on or off the site shall be conditioned upon
<br />compliance by the Contractor with procedures satisfactory to the Owner to establish the Owner's title to such
<br />materials and equipment or otherwise protect the Owner's interest, and shall include the costs of applicable
<br />insurance, storage and transportation to the site for such materials and equipment stored off the site.
<br />AIA Docunent A2OL - 2001. Copyright o 1911, 1915, 19L8, L925, 1,93'7, 1,957, 1958, 1961, 1963, 1966, I9'10, 1916, 798'l' 199
<br />rights reserved. "The Anerican Institute of Architects," "American Institute of Architects," "AIA," the AIA Logo, and "
<br />Documents', are tradenarks of 1he Amelican Institute of Architects. This draft was produced at 09:51:37 PT o^ 05/13/2024
<br />tto,4lO4243O4? whlch expires o^ 06/tO/2024, is not for resale, is licensed for one-tj.me use only, and nay only be used i
<br />the AIA Contract Documentso Terms of Service. To report copyright violations, e-mail docinfocaiacontracts.com.
<br />Uger Notea:
<br />? and 200?. AII
<br />AIA Contract.
<br />under order
<br />n accordance with
<br />(rr6491601?)
<br />23
|