Laserfiche WebLink
7 Offshore ltems, RCW 39.25 <br />8 Drug Free Workplace, comply with Federal, State and local laws including Drug-Free <br />Workplace Act of 1988. <br />9 Tobacco-Free Environment, RCW 28A.210.310. <br />10 Safety Standards, RCW 49.17 and Chapters 296-155 WAC. <br />LL Apprenticeship Utilization, RCW 39.04.320. <br />The Contractor shall provide the following information to the Owner: <br />1. Contractor name and address. <br />2. Contract number. <br />3. Project name. <br />4. Contract value. <br />5. The date of the Contractor's notice to proceed. <br />L3.9.2 Comply with all applicable Federal, State, County and municipal laws and <br />ordinances, including but not limited to, the following (latest adopted editions): <br />1.. lnternational Building Code <br />2. lnternational Plumbing Code <br />3. lnternational Mechanical Code <br />4. National Electrical Code <br />5. Washington I nd ustria I Safety and Health Administration regu lations. <br />6. Other Federal and State safety regulations. <br />7. Washington Administrative Code Chapter 51-20. <br />8. lnternational Fire Code. <br />9. Adaptations or modifications of any of the above by State and local ordinance. <br />13.9.3 The Contractor shall hereby protect and hold harmless the Ownerfrom all damages and extra costs <br />arising from violation of any laws, rules and regulations. <br />ARTICLE 15 - CLAIMS AND DISPUTES <br />Delete Subparagraph L5.1.2 and substitute the following: <br />15.L.zTime Limits on Claims. A Claim, including those in connection with concealed or <br />unknown conditions by either party must be made by written notice to the Architect <br />within ten (10) days from the date of the occurrence of the event or discovery of the <br />condition giving rise to the Claim or within ten (L0) days from the date that the Claimant <br />knew or should have known of the event or condition. Unless the Claim is made within <br />the aforementioned time requirements, it shall be deemed to be waived. The written <br />notice of Claim shall include a factorial statement of the basis for the Claim, pertinent <br />dates, contract provisions offered in support of the Claim, additional materials offered in <br />support of the Claim, and the nature of the resolution sought by the Claimant. The <br />Architect will not consider, and the Owner shall not be responsible or liable for, any <br />claims from subcontractors, suppliers, manufacturers or other persons or entities not a <br />party to this contract. Once a Claim is made, the Claimant shall cooperate with the <br />Architect and the party against whom the Claim is made in order to mitigate the alleged <br />or potential damages, delay or other adverse consequences arising out of the condition. <br />Kittitas County - Lower ValleY <br />Transfer Station <br />Supplementary General <br />Conditions of the Contract <br />June 1.8,2024 <br />27 of 24