AIA 101 Agreement 08302024 - Laserfiche WebLink

Home Browse Search

7 Offshore Items, RCW 39.25 8 Drug Free Workplace, comply with Federal, State and local laws including Drug -Free Workplace Act of 1988. 9 Tobacco -Free Environment, RCW 28A.210.310. 10 Safety Standards, RCW 49.17 and Chapters 296-155 WAC. 11 Apprenticeship Utilization, RCW 39.04.320. The Contractor shall provide the following information to the Owner: 1. Contractor name and address. 2. Contract number. 3. Project name. 4. Contract value. 5. The date of the Contractor's notice to proceed. 13.9.2 Comply with all applicable Federal, State, County and municipal laws and ordinances, including but not limited to, the following (latest adopted editions): 1. International Building Code 2. International Plumbing Code 3. International Mechanical Code 4. National Electrical Code 5. Washington Industrial Safety and Health Administration regulations. 6. Other Federal and State safety regulations. 7. Washington Administrative Code Chapter 51-20. 8. International Fire Code. 9. Adaptations or modifications of any of the above by State and local ordinance. 13.9.3 The Contractor shall hereby protect and hold harmless the Owner from all damages and extra costs arising from violation of any laws, rules and regulations. ARTICLE 15 - CLAIMS AND DISPUTES Delete Subparagraph 15.1.2 and substitute the following: 15.1.2 Time Limits on Claims. A Claim, including those in connection with concealed or unknown conditions by either party must be made by written notice to the Architect within ten (10) days from the date of the occurrence of the event or discovery of the condition giving rise to the Claim or within ten (10) days from the date that the Claimant knew or should have known of the event or condition. Unless the Claim is made within the aforementioned time requirements, it shall be deemed to be waived. The written notice of Claim shall include a factorial statement of the basis for the Claim, pertinent dates, contract provisions offered in support of the Claim, additional materials offered in support of the Claim, and the nature of the resolution sought by the Claimant. The Architect will not consider, and the Owner shall not be responsible or liable for, any claims from subcontractors, suppliers, manufacturers or other persons or entities not a party to this contract. Once a Claim is made, the Claimant shall cooperate with the Architect and the party against whom the Claim is made in order to mitigate the alleged or potential damages, delay or other adverse consequences arising out of the condition. Kittitas County — Lower Valley 21 of 24 Supplementary General Transfer Station Conditions of the Contract June 18. 2024