Laserfiche WebLink
23.3. Deta Claim <br />The contractor shall not be entitled to claim any such additional <br />compensation, or extension of time, unless within thirty (30) days of the <br />completion of the portion of the work from which the claim arose, and before <br />final payment by the coung, the contractor has given the county a detailed <br />written statement of each element of cost or other compensation requested <br />and of all elements of additional time required, and copies of any supporting <br />documents evidencing the amount or extension of time claimed to be due. <br />24. Ownership of ltems Produced: <br />All writings, programs, data, public records or other materials prepared by the Contractor <br />and/or its consultants or sub-Contractors, in connection with performance of this Agreement <br />shall be the sole and absolute propefi of the County and/or DSHS. <br />25. Confidentialitv: <br />The Contractor, its employees, Sub-Contractors, and their employees shall maintain the <br />confidentiality of all information provided by the County or DSHS br acquired by the <br />Contractor in performance of thisAgreement, except: 1) as provided below, 2) upon the prior <br />written consent of the Kittitas County Prosecuting Attorney; or 3) upon an order entered by <br />a court after having acquired jurisdiction over the County. Contractor shall immediately give <br />to the County notice of any judicial proceedings seeking disclosure of such information. <br />Contractor shall indemniff and hold harmless the County, its Additional lnsured's, officials, <br />agents or employees from all loss or expense, including, but not limited to settlements, <br />judgments, setoffs, attorneys' fees and costs resulting from Contractor's breach of this <br />provision. <br />25.1 The Contractor shall not use, publish, transfer, sell or otherwise disclose any <br />Confidential lnformation gained by reason of this Agreement for any purpose <br />that is not directly connected with the performance of the services <br />contemplated hereunder, except: <br />251.1 As provided by law; or <br />25J.21n the case of Personal lnformation, as provided by law orwith the prior <br />written consent of the person or personal representative of the person <br />who is the subject of the Fersonal information. <br />25.2 The Contractor shall protect and maintain all Confidential lnformation gained <br />by reason of this Agreement against unauthorized use, access, disclosure, <br />modification or loss. This duty requires the Contractor to employ reasonable <br />security measures, which include restricting access to the Confidential <br />lnformation by: <br />Professional Services Agreement <br />Page 1 1