Laserfiche WebLink
County at the earliest possible time in order that such matters may be settled <br /> or other appropriate action promptly taken. Except for such objections as are <br /> made of record in the manner hereinafter specified and within the time limits <br /> stated, the records, orders, instructions, and decisions of the Kittitas County <br /> Commissioners shall be final and conclusive. <br /> 22.2 Notice of Potential Claims <br /> The Contractor shall not be entitled to additional compensation which <br /> otherwise may be payable, or to extension of time for (1) any act or failure to <br /> act by the County, or (2) the happening of any event or occurrence, unless <br /> the Contractor has given the County a written Notice of Potential Claim within <br /> ten (10) days of the commencement of the act, failure, or event giving rise to <br /> the claim, and before final payment by the County. The written Notice of <br /> Potential Claim shall set forth the reasons for which the Contractor believes <br /> additional compensation or extension of time is due, the nature of the cost <br /> involved,and insofar as possible,the amount of the potential claim. Contractor <br /> shall keep full and complete daily records of the work performed, labor and <br /> material used, and all costs and additional time claimed to be additional. <br /> 22.3. Detailed Claim <br /> The Contractor shall not be entitled to claim any such additional <br /> compensation, or extension of time, unless within thirty (30) days of the <br /> completion of the portion of the work from which the claim arose, and before <br /> final payment by the County, the Contractor has given the County a detailed <br /> written statement of each element of cost or other compensation requested <br /> and of all elements of additional time required, and copies of any supporting <br /> documents evidencing the amount or extension of time claimed to be due. <br /> 23. Ownership of Items Produced: <br /> All writings, programs, data, public records or other materials prepared by the Contractor <br /> and/or its consultants or sub-Contractors, in connection with performance of this Agreement <br /> shall be the sole and absolute property of the County. <br /> 24. Confidentiality: <br /> The Contractor, its employees, sub-Contractors, and their employees shall maintain the <br /> confidentiality of all information provided by the County or acquired by the Contractor in <br /> performance of this Agreement, except upon the prior written consent of the Kittitas County <br /> Prosecuting Attorney or an order entered by a court after having acquired jurisdiction over <br /> the County. Contractor shall immediately give to the County notice of any judicial <br /> proceedings seeking disclosure of such information. Contractor shall indemnify and hold <br /> harmless the County, its Additional Insureds, officials, agents or employees from all loss or <br /> expense, including, but not limited to settlements, judgments, setoffs, attorneys' fees and <br /> costs resulting from Contractor's breach of this provision. <br /> Professional Services Agreement(rev.09/24/2018) <br /> Page 10 of 19 <br />