PSA Compass Direct Healthcare - Laserfiche WebLink

Home Browse Search

22.2 Notioe.of Potentiat QlaiqrsThe Contractor shall not be entitlad to additional compensation which othenrvise Tay ne payable, or to extension of time for (1) any aA or failure toact !Y the County, or (2) the happening of any event oi occurrence, unless the Contrador has given the County a written Notice of Potential Claim within ten (10) days of the commencement of the act, failure, or event giving risi iothe claim, end before final payment by the County. The writtln Nitice of Potential Claim shallset forth the reasons br whiclrthe Contractor believes additional compensation or extension of time is due, the nature of Sre coat involved, and insofaras possible, the amountof the potentialclaim. Contrac,tor shallkeep fulland complete daily records of the work performed, labor andmaterialused, and allcosts and additionaltime claimed to ba additional. 22.3. Delaited Ctairq The Contractor shall not be entitled to claim any sucfr additional compensation, or extension of time, unles within thirty (30) days of the completion of lhe portion of the vrcrk frorn wtrich the clalm aroie, and before finalpayment by the County, the Contrador has given the Couniy a detailed written statement of each element of cost or other compensatiori requested and of all elements of addilional ffme rquired, and copibs of any supporting documents evidencing he amountorextension of timi claimed tb be iue. - 23. Ownership of ltems Produoed: All writings, programs, data, public records or o0pr materials prepared by the Contrastorard/orits consultants or sub-Contractors,-in connection wi0r pe*orirance oittrisAgreement shallbe the sob and absolute property of the Coung. 24. Conlldenliality: The Contractor, its employees, sub-Conkadors, and their employees shall mainlain theconfdentiality of all infurmalion provlded by the County or ac{uir6U by the Contractor inperformance of this Agreement, exoept upoh the prlor w-ritten cohsent of ttre Kittitas CountyPrcsecuting Attorney or an order entered by a court after haviqg acquireo juriJidion or",tte County. Contracfor shall immediatelV giv_e to tre Couity riotice'of any judicial proceedirgs seeking disclosure sf such information, Contrac.tor itral inAemnfi-aiO no6harmless the County, its Additional lnsureds, officials, agenk or employeet troni all loss orexpense, including, but not limited to setilements, judgments, setoits, attomeys,fees andmb resulting from Contracto/s breach of this provision. To the extent that any information obtained by itre Gontnac'tor is required to be shared withor provided to others by lhe terms of lhe Statement of lhe Woir, this provision is notbreaclred by such acts. 25. Notice: Prcfbsimal Serylces Agreerrnt (r€v. OU24nO1g) Pege I of 17