Laserfiche WebLink
22.2 Notice of Potential Claims <br />The Contractor shall not be entitled to additional compensation which <br />otherwise may be payable, or to extension of time for (1) any act or failure to <br />act by the County, or (2) the happening of any event or occurrence, unless <br />the Contractor has given the County a written Notice of Potential Claim within <br />ten (10) days of the commencement of the act, failure, oi' event giving rise to <br />the claim, and before final payment by the County. The written Nbtice of <br />Potential Claim shall set forth the reasons for which the Contractor believes <br />additional compensation or extension of time is due, the nature of the cost <br />involved, and insofar as possible, the amount of the potential claim. Contractor <br />shall keep full and complete daily records of the work performed, labor and <br />material used, and allcosts and additionaltime claimed to be additional. <br />223. Detailed Claim <br />The Contractor shall not be entitled to claim any such additional <br />compensation, or extension of time, unless within thirty (30) days of the <br />completion of the portion of the work from which the claim arose, and before <br />final payment by the County, the Contractor has given the County a detailed <br />written statement of each element of cost or other compensation requested <br />and of all elements of additional time required, and copies of any supporting <br />documents evidencing the amount or extension of time claimed to be due. <br />23. Ownership of ltems Produced: <br />All writings, programs, data, public records or other materials prepared by the Contractor <br />and/or its consultants or sub-Contractors, in connection with performance oithis Agreement <br />shall be the sole and absolute property of the County. <br />24. Confidentialitv: <br />The Contractor, its employees, sub-Contractors, and their employees shall maintain the <br />confidentiality of all information provided by the County or acquired by the Contractor in <br />performance of this Agreement, except upon the prior written consent oi tfre Kittitas County <br />Prosecuting Attorney or an order entered by a court after having acquired jurisdiction overthe County. Contractor shall immediately give to the County notice of any judicial <br />proceedings seeking disclosure of such information. Contractor shall indemnify anO frotO <br />harmless the County, its Additional lnsureds, officials, agents or employees from all loss or <br />expense, including, but not limited to settlements, judgments, setoffs, attorneys'fees and <br />costs resulting from Contractor's breach of this provision. <br />To the extent that any information obtained by the Contractor is required to be shared withor provided to others by the terms of the Statement of the Work, this provision is not <br />breached by such acts. <br />25. Notice <br />Professional Services Ag ree ment (r ev . 09124 1201 g) <br />Page 9 of 17