PSA Schuknecht's Polygraph Services with Judge's signatures

Home Browse Search

made of record in the manner hereinafter specifiedand within the time limits stated, the records, orders, instructions, anddecisions of the Kittitas County Commissioners shall be final and conclusive. 22.2 Notice of Potential Claims The Contractorshall not be entitled to additional compensation whichotherwise may be payable, or to extension of time for (1) any act or failure to act by the County, or (2) the happening of any event or occurrence, unless the Contractor has given the County a written Notice of Potential Claim within ten (10) days of the commencement of the act, failure, or event giving rise to the claim, and before final payment by the County.The written Notice of Potential Claim shall set forththe reasons for which the Contractor believes additional compensation or extension of time is due, the nature of the cost involved,and insofar aspossible, the amount of the potential claim. Contractor shall keep full and complete dailyrecords of thework performed, labor and material used, and all costs and additional time claimed to be additional. 22.3. Detailed Claim The Contractor shall not be entitled to claim any such additionalcompensation, or extension of time, unless within thirty (30) days of the completion of the portion of the work from which the claim arose, and before final payment by the County, the Contractor has given the County a detailed written statement of each element of cost orother compensation requested and of all elements of additional time required, and copies of any supporting documents evidencingthe amount or extension of time claimed to be due. 23. Ownership of Items Produced: All writings, programs, data, public records or other materials prepared by the Contractor and/or its consultants or sub -Contractors, in connection with performance of this Agreement shall be the sole and absolute property of the County. 24. Confidentiality: The Contractor, its employees, sub -Contractors, and their employees shall maintain the confidentiality of all information provided by the County or acquired by the Contractor in performance of this Agreement, except upon the prior written consent of the Kittitas County Prosecuting Attorney or an order entered by a court after having acquired jurisdiction over the County. Contractor shall immediately give to the County notice of any judicial proceedings seeking disclosure of such information. Contractor shall indemnify and hold harmless the County, its Additional Insureds, officials, agents or employees from all loss or expense, including, but not limited to settlements, judgments, setoffs, attomeys' fees and costs resulting from Contractor's breach of this provision. Professional Services Agreement (rev. 09/24/2018) Page 9 of 18