PSA Thomas Rowe - Laserfiche WebLink

Home Browse Search

County at the earliest possible time in orderthat such matters may be settled or other appropriate action proqnptly taken. Except for such objections as are made of record in the manner hereinafter specified and within the time limits stated, the records, orders, instructions, and decisions of the Kittitas County Commissioners shall be final and conclusive. 22.2 Notice of Potential Claims The contractor shall not be entitled to additional compensation which otherwise may be payable, or to extension of time for (1) any act or failure to act by the County, or (2) the happening of any event or occurrence, unless the Contractor has given the County a wriften Notice of Potential Claim within ten (10) days of the commencement of the act, failure, or event giving rise to the claim, and before finalpayment by the county. The written Notice of Potential Claim shall set forth the reasons for which the Contractor believes additional compensation or extension of time is due, the nature of the cost involved, and insofar as possible, the amount of the potential claim. Contractor shall keep full and complete daily records of the work performed, labor and material used, and all costs and additional time claimed to be additional. 223. Detaibd Claim The Contractor shall not be entitled to claim any such additional compensation, or extension of time, unless within thirty (30) days of the completion of the portion of the work from which the claim arose, and before final payment by the County, the Contractor has given the County a detailed wriften statement 6f each element of cosl or other compensation requested and of all elements of additional time required, and copies of any supporting documents evidencing the amount or extension of time claimeU tb Ue iue. 24. Confidentialitv: The Contractor, its employees, sub-Contractors, and their employees shall maintain the confidentiality of all information provided by the County or acquired by the Contractor in performance of this Agreement, except upon the prior written consent of the Kittitas Cgunty Prosecuting Attorney or an order entered by a court afrer having acquired jurisdiction over the County. Contractor shall immediately give to the County notice of any judicial proceedings seeking disclosure of such information. Contractor shall indemnifir and hold harmless the County, its Additional lnsureds, officials, agents or employees from all loss or expense, including, but not limited,to settlements, judgments, setofb, attorneys' fees and costs resulting from Contractor's brdach of this provision. Professional Services Agreement (rev, Agn4l2018) Page 9 of 17 23. Ownership of ltems Produced: All writings, programs, data, public records or other materials prepared by the Contractor andlor its consultants or sub-Contractors, in connection with perfoimance of this Agreement shall be the sole and absolute property of the County.