SH19-019 BLM 2019 Contract - Laserfiche WebLink

Home Browse Search

Kittitas County Law Enforcement Services, Washington State PURCHASE ORDER NO. 140L4319P0094 BLM-WA Spokane District Office Page 25 of 26 1510-52.211-70 BLM - VARIATION IN ESTIMATED QUANTITY (MAY 1987), 52.211-70 (DEVIATION) If the quantity of the unit -priced item in this contract is an estimated quantity and the actual quantity of the unit - priced item varies more than 20 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 120 percent or below 80 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract. Upon the receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgment of the Contracting Officer, is justified. (End of clause) (End of Contract Clauses)