Laserfiche WebLink
<br />Professional Services Agreement <br />Page 9 <br /> 22.3. Detailed Claim <br /> The Contractor shall not be entitled to claim any such additional <br />compensation, or extension of time, unless within thirty (30) days of the <br />completion of the portion of the work from which the claim arose, and before <br />final payment by the County, the Contractor has given the County a detailed <br />written statement of each element of cost or other compensation requested <br />and of all elements of additional time required, and copies of any supporting <br />documents evidencing the amount or extension of time claimed to be due. <br /> <br />23. Ownership of Items Produced: <br />All writings, programs, data, public records or other materials prepared by the Contractor <br />and/or its consultants or sub-Contractors, in connection with performance of this <br />Agreement shall be the sole and absolute property of the County. <br /> <br />24. Confidentiality: <br />The Contractor, its employees, sub-Contractors, and their employees shall maintain the <br />confidentiality of all information provided by the County or acquired by the Contractor in <br />performance of this Agreement, except upon the prior written consent of the Kittitas <br />County Prosecuting Attorney or an order entered by a court after having acquired <br />jurisdiction over the County. Contractor shall immediately give to the County notice of any <br />judicial proceedings seeking disclosure of such information. Contractor shall indemnify <br />and hold harmless the County, its Additional Insured’s, officials, agents or employees from <br />all loss or expense, including, but not limited to settlements, judgments, setoffs, attorneys' <br />fees and costs resulting from Contractor’s breach of this provision. <br /> <br />25. Notice: <br />Except as set forth elsewhere in the Agreement, for all purposes under this Agreement, <br />except service of process, notice shall be given by the Contractor to the department head <br />of the department for whom services are rendered, and to the Kittitas County <br />Commissioners, 205 W 5th Ave, Suite 108, Ellensburg, WA 98926. Notice to the <br />Contractor for all purposes under this Agreement shall be given to the address reflected on <br />the signature page. Notice may be given by delivery or by depositing in the U.S. Mail, first <br />class, postage prepaid. <br /> <br />26. Severability: <br />If any term or condition of this Agreement or the application thereof to any person(s) or <br />circumstances is held invalid, such invalidity shall not affect other terms, conditions or <br />applications which can be given effect without the invalid term, condition or application. To <br />this end, the terms and conditions of this Agreement are declared severable. <br /> <br />27. Miscellaneous: <br /> 27.1 The County’s failure or delay to insist upon strict performance of any of the <br />provisions of this Agreement or to exercise any rights or remedies under this <br />Agreement shall not be construed as a waiver or relinquishment to any